Agreement Terms Conditions - Blubuzz media
TERMS & CONDITION
Please read through our Terms and Conditions, we ask that you do not use our website or service until you have familiarised yourself with them. If you are using or have used our service it is understood that you have agreed to the terms set forth on this page. It is important that you check back here regularly. Your acceptance of which is agreed from the moment you agree and pay Website advance payment.
We have tried to keep these Terms and Conditions brief, easy to understand, and as straightforward as possible. If you have any questions however, please do not hesitate to contact us on call + 918696880033and on email support@Blubuzzmedia.com
Project Payment Terms
Payment for our website projects is made over three stages:
Stage One: Prior to commencing work we must receive a 70% deposit/advance for your website project.
Stage Two: After received Advance payment. We will have start to create full website using content, images and navigation that you supplied to us. If we have not received content for your website at the time of design approval, we will load dummy content onto your website.
Remaining 25% payment of the project quotation total due upon completion of the work, prior to upload to the server or release of materials.
Please make sure website creating time period count after payment made of each stage. Example if you pay advance we will start project and show you first Design. After second payment we will star work on complete website.
Search Engines Submission
We do not guarantee any specific position in search engine results for your website. We perform basic search engine optimization according to current best practice.
BACKUPS
You are responsible for maintaining your own backups with respect to your website and we will not be liable for restoring any client data or client websites except to the extent that such data loss arises out of a negligent act or omission by us.
E-COMMERCE
You are responsible for complying with all relevant laws relating to e-commerce, and to the full extent permitted by law will hold harmless, protect, and defend and indemnify Blubuzz media ® and its subcontractors from any claim, penalty, tax, tariff loss or damage arising from your or your clients’ use of Internet electronic commerce.
Training
Our expert team would be providing training to the client’s team via online interactions but that would depend on the request of the client.
Delays with respect to projects
Unreasonable delays from client side in providing the required feedback/information/data to finish the project shall exempt Blubuzz media from meeting the timelines mentioned in the quote. In case client does not provide required details/data/information for more than 15 working days, client authorizes Blubuzz media to forfeit/fine/penalty the payments made towards this project.
In case, during the project duration, the client does not maintain communication with Blubuzz media for more than 30 calendar days, client agrees that the project/services shall be deemed as received and accepted by the client, and the client further authorizes Blubuzz media to mark the project completed and invoice the client for remaining un-invoiced amount as per the total project price agreed.
However, Client can instruct Blubuzz media to put project on hold provided:
Client agrees to pay project resumption fee of 25% of the total project price.
‘on-hold’ period does not exceed 2 calendar months
Client agrees the professionals attached to the project (Project Team Structure) may be different from originally agreed.
Client agrees to pay this project resumption fee every time a project is being put ‘on-hold’
Payment Delay for domain and hosting:
If client not able to pay domain and hosting renewal cost on time then it will be expire. And if client want renewed expire domain and hosting then client applicable for Late Fee Charge.
We are not responsible for lost data, files and database. Should a client require access to the files on the suspended account hosting payment must be made in full payment plus late fee.
3 month free technical support
Blubuzz media offers 3 month free support. After 3 month client can choose our maintenance package.
Site maintenance:
Unless otherwise agreed in writing, following services will be separately billed after the website has been made live:
Content updates
Refinements and logical tweaks to the website, which were not planned/approved by client earlier.
Content presentation and design updates that were not planned/approved by client earlier.
Photographs and Images:
It’s overall responsibility of client to provide the developing team with appropriate Photographs and Images without the issue of copyrights. All the graphic should be handed over on the stipulated time frame so that no delays could occur. Our company would not be taking any responsibility on issues with respect to stealing pictures.
Material:
All material supplied by the client shall remain client’s property. Blubuzz media rightfully believes that this material belongs to the client and that it does not breach any copyright laws. Under no circumstances shall Blubuzz media be held responsible for any claims, damages, and loss of profit or reputation caused to client due to the use of material provided by the client.
3rd Party Add-ons/services/applications:
All third party costs arising from the registration of a domain name/Hosting/purchase of third party utilities/services shall be met by the Client and are payable to Blubuzz media before a Start project. Examples of 3rd party fees are as under:
Domain Names
a) Server Space Hosting Fees
b) SSL Certificates
c) Backup Services
d) 3rd Party APIs, if any, required by ‘Client’ to be integrated with the work ordered.
e) 3rd Party Plugins/Scripts/Applications/Software/Widgets/Services, if any, required by ‘Client’ to be integrated with the work ordered.
f) Payment Gateways Signup and Recurring Fees.
Legal Bits:
We cannot guarantee that the functions contained within any web page (or part of your website design), will always be error free, and therefore we will not be liable in any way whatsoever to you for any third party damages, including lost profits, lost savings, or other incidental, consequential or special damages arising out of the operation of or inability to operate this web site and any other web pages, even if you have advised us of the possibilities of such damages.
Content Management Systems:
a) All packages with the exception of our basic package (Start Up) will be developed using a Content Management System (CMS).
b) In order to maintain compatibility between clients the company now use the WordPress Platform exclusively as our CMS of choice. Ecommerce stores use different management systems depending on the scale and complexity of the Project.
c) However, in some instances, the company may build a bespoke solution, depending on the exact requirements of the Project.
d) Any associated or additional fees, such as installation, setup, testing and introductory training pertaining to Content Management Systems or E-Commerce Management Systems are covered within your chosen package.
General:
a) A website will not launch until a standing order or BACS payment has been set up, unless special agreement has been reached in advance.
b) Additional costs for extra features and/or additional design costs, not covered by our standard packages, will be agreed and invoiced before the website goes live.
c) If the Client does not respond to the Company’s request to discuss or choose ongoing support options, the client will automatically be placed on what the company feels is the most appropriate support package.
d) A small admin fee is payable for switching the client to another hosting provider.
e) There may be an additional fee for any design changes requested after the initial agreed design has been signed off.
f) The Company is not responsible for writing or inputting any text copy unless this has been specified by the client.
g) If you are hosting the website elsewhere, the Company cannot guarantee that the website is fully compatible with all hosting provider’s server operating systems, especially any contact forms, Content Management Systems, database driven websites, etc.
h) The company do not offer any technical support for any other web site hosting company that you may choose (if you elect not to host the website with us).
i) If any provision of this agreement shall be unlawful, void, or for any reason unenforceable, then that provision shall be deemed severable from this agreement and shall not affect the validity and enforceability of any remaining provisions. Just the same as a fine, you cannot transfer this contract to anyone else without our consent or permission.
Changes to these Terms and Conditions
Blubuzz Media reserve the right to add, delete, or modify any provision of these ‘Web Design Terms and Agreement’ at any time without notice.
Failure to receive notification of a change does not make those changes invalid. These Terms and Conditions will always be available to download or print from our website.
Client/Advertiser/subscriber signing the contract form overleaf is deemed to have read and understood the foregoing terms and conditions before signing the same and therefore cannot plead ignorance of the said terms and conditions.
The agreement is subject to force majeure clause.
In case of disputes the courts in Jaipur only will have jurisdiction.
